Public Notices

Construction Service Bids

Advertisement for Bids

For Construction at Monroe Municipal Airport Monroe, Wisconsin Project no. AIP 3-55-0050-08/EFT1000

Sealed proposals for the work described herein will be received until 2:00 p.m., local time, Thursday, July 11, 2019, by the Wisconsin Department of Transportation, Bureau of Aeronautics, on behalf of the Secretary, authorized agent for Monroe Municipal Airport, in accordance with Wis. Stat. §114.32(3) (1983), at the office of the Bureau of Aeronautics, 4822 Madison Yards Way, 5th floor South, Madison, Wisconsin 53705; whereupon the sealed proposals received as provided above will be publicly opened and read. Bidders wishing to submit their bid by mail may do so at their own risk. Bids received by the Bureau of Aeronautics later than the time set forth above will be returned unopened. The correct mailing address is: Wisconsin Department of Transportation, Bureau of Aeronautics, P.O. Box 7914, Madison, Wisconsin 53707-7914. The correct shipping address is: WI Department of Transportation, Bureau of Aeronautics, 4822 Madison Yards Way, 5th floor South, Madison, Wisconsin 53705. Sending bid documents by Priority Mail may not guarantee timely delivery to our office. Building Security at Hill Farms State Transportation Building: Security procedures are in place at the Hill Farms State Transportation Building in Madison. Please allow extra time for hand delivering bids. Description of work: BASE BID: Reconstruction of Rwy 12-30, including pulverizing and relaying asphaltic pavement, grading, HMA pavement, pavement markings, brush and tree clearing, landscaping, removal of Taxiway A1, and all incidental items necessary to complete the work as shown on the plans. ALTERNATE A: Reconstruction of taxiways and apron, including pulverizing and relaying asphaltic pavement, grading, HMA pavement, pavement markings, landscaping, and all incidental items necessary to complete the work as shown on the plans. ALTERNATE B: Airfield lighting, cable, conduit, regulator, REILs, and signs for Rwy 12-30. Estimate of major quantities: BASE BID: 17,000 CY Common Excavation; 57,576 SY Pulverize and Relay Existing Pavement; 14,917 CY Salvage and Place Existing Base Aggregate; 11,800 TON HMA Pavement 4 MT 58-28 S; 22,260 SF Painting; 53,700 SY Salvaged Topsoil and Restoration. ALTERNATE A: 5,000 CY Common Excavation; 10,226 SY Pulverize and Relay Existing Pavement 1,985 CY Salvage and Place Existing Base Aggregate; 2,500 TON HMA Pavement 4 MT 58-28 S; 230 SF Painting; 5,900 SY Salvaged Topsoil and Restoration. ALTERNATE B: 11,790 LF 5,000 Volt Cable; 10,760 LF Counterpoise; 11,390 LF Polyethylene Duct; 63 EA MIRL LED; 3 EA Guidance Signs; 1 EA Regulator; 2 LS Adjusting PAPIs; 2 EA REILs (per set); 1 LS Rotating Airport Beacon DBE Goal: 2.84% Contract Completion Time: 55 Working Days (See Specials) Proposals: Proposal forms are included with the plans and specifications, and are subject to the provisions of Wis. Stat. §66.0901(7) (1999). Plans and specifications: Plans and specifications which govern the work are on file and available for purchase at the office of Blue Print Services, 2350 West Pershing St. Appleton, WI. https://www.bpserviceplanroom.com/ https://omnni.com/bidding/ Plans and specifications which govern the work are on file and available for office examination at the office of Aaron Stewart, OMNNI Associates, Inc. One Systems Drive, Appleton, WI 54914; the office of the Wisconsin Bureau of Aeronautics 4822 Madison Yards Way, 5th floor South, Madison, Wisconsin 53705; the office of the airport manager, Rob Driver, W4711 WI-59, Monroe, WI 53566; the office of the Wisconsin Transportation Builders Association, 1 East Main Street, Suite 300, Madison, Wisconsin; and WisDOT Supportive Services, 6150 W. Fond du Lac Avenue, Milwaukee, Wisconsin. Proposal Submittal: This contract is NOT electronically bid. A paper bid submittal is required. Contractors electing to obtain plans & specifications via CD are still required to submit a paper bid proposal. The CD will include a blank electronic spreadsheet that is available to be used to complete the schedule of prices. The CD will be accompanied by the appropriate paper forms that need to be included with the bid submittal. The specifications and CD “readme” files will contain specific instructions on how to complete the bid proposal. Proposal guaranty: Each proposal must be accompanied by a bid bond, certificate of annual bid bond, a certified check, bank's draft, bank's check, or postal money order made payable to the Wisconsin Department of Transportation Secretary for 5% of the total amount bid. Certified checks may be drawn on the account of the bidder submitting the proposal. Qualification of bidders: The Bureau of Project Development “Prequalification Statement” (AKA: “Highways”) will apply. The proper forms can be found at: https://wisconsindot.gov/Pages/doing-bus/contractors/hcci/prequal.aspx Bid proposals will be opened only from those who have established their qualifications for the work being bid upon. If a prospective bidder has submitted a current statement and received approval from the department, a re-submittal for this project is not required. Any prospective bidder who has not previously established their qualifications must file a pre-qualification statement on the proper forms and be received by the department no later than 12:00 noon, local time, Friday, June 28, 2019. Only prime or general contractors submitting the bid need to be prequalified; subcontractors do not need to be prequalified. The qualification statement is a sworn statement and consist of information relating to financial ability, equipment, and experience in the work prescribed in this proposal. The statement shall be in writing on the proper standard form furnished by the department. The department will evaluate the statement and determine acceptability prior to bid allowance. Each bidder is required to submit a “Bidder's Request to Bid/Current Workload” form for this project, and it should be received by the bureau no later than 24 hours prior to the bid opening. Bidders are urged to submit this form as early as possible to determine eligibility prior to preparing the bidding proposal. Failure to submit the request to bid/current workload form may result in the rejection of the bid. Federal Requirements: This project is federally funded and federal provisions and requirements apply. Federal provisions made part of, but not limited to this contract include: Buy American Preference, Foreign Trade Restriction, Davis Bacon, Affirmative Action, Governmentwide Debarment and Suspension, Governmentwide Requirements for Drug-free Workplace. Hours of labor and minimum wage rates: Pursuant to regulations provided by applicable federal and/or state laws, the hours of labor and minimum wage rates are set forth in the proposal. Affirmative action: The department hereby notifies all bidders that it will affirmatively insure that in any contract entered into pursuant to this advertisement, disadvantaged business enterprises will be afforded full opportunity to submit bids in response to this invitation and will not be discriminated against on the grounds of race, color, sex, or national origin in consideration for an award. Affidavit of non-collusion: A required affidavit of non-collusion will be incorporated as part of the proposal cover provided to each prospective bidder. Failure to complete the sworn statement makes the bid non-responsive and ineligible for award consideration. By signing the proposal cover each bidder by or on behalf of the person, firm, association, or corporation submitting the bid, certifies that such person, firm, association, or corporation has not, either directly or indirectly, entered into agreement, participated in any collusion, or otherwise taken any action, in restraint of free competitive bidding in connection with the submitted bid. This sworn statement shall be executed and sworn to by the bidder before a person who is authorized by the laws of the state to administer oaths. Pre-bid conference: A pre-bid conference will be held on Wednesday, June 26th, 2019 at 10:30 a.m. at the Monroe Municipal Airport Terminal Building. The purpose of the meeting will be to familiarize all concerned persons with the project and conditions at the airport. For further information, contact Aaron Stewart, OMNNI Associates, at 920-735-6900, email aaron.stewart@omnni.com, FAX 920-830-6100.

City of Monroe, Wisconsin Represented by Craig Thompson, Secretary Department of Transportation Sponsor's Authorized Agent

(June 19, 26, 2019) WNAXLP

Debtors Creditors

NOTICE TO CREDITORS (INFORMAL ADMINISTRATION) CASE NO. 19-PR-35

STATE OF WISCONSIN, CIRCUIT COURT, GREEN COUNTY

IN THE MATTER OF THE ESTATE OF BRIAN L. LEIGHTY Deceased PLEASE TAKE NOTICE: 1. An application for informal administration was filed. 2. The decedent, with date of birth May 18, 1963 and date of death May 8, 2019 was domiciled in Green County, State of Wisconsin, with a mailing address of 219 W. Main Street, Browntown, WI 53522. 3. All interested persons waived notice. 4. The deadline for filing a claim against the decedent’s estate is September 17, 2019. 5. A claim may be filed at the Green County Justice Center, 2841 6th Street, Monroe, Wisconsin.

Thomas J. Vale Circuit Court Judge June 7, 2019

Attorney Todd W. Schluesche Kittelsen, Barry, Wellington, Thompson & Schluesche, S.C. 916 17th Ave. Box 710 Monroe, WI 53566 608-325-2191 Bar Number 01024392

(June 12, 19, 26, 2019) WNAXLP

Miscellaneous

PUBLICATION SUMMONS Case No. 19-CV-000047 The Honorable James R. Beer Case Code 30404 (Foreclosure of Mortgage) The amount claimed exceeds $10,000.00
STATE OF WISCONSIN CIRCUIT COURT GREEN COUNTY

AMERIHOME MORTGAGE COMPANY, LLC 425 PHILLIPS BLVD.,FC-236 EWING, NJ 08618

Plaintiff, vs. ASHLEY N. HARPER N8389 COUNTY ROAD X BELLEVILLE, WI 53508-9622
BRIAN L. LEDESMA

N8389 COUNTY ROAD X BELLEVILLE, WI 53508-9622 JANE DOE LEDESMA N8389 COUNTY ROAD X BELLEVILLE, WI 53508-9622 JOHN DOE HARPER N8389 COUNTY ROAD X BELLEVILLE, WI 53508-9622

Defendants. THE STATE OF WISCONSIN To each person named above as a defendant: You are hereby notified that the plaintiff named above has filed a lawsuit or other legal action against you. Within 40 days after June 19, 2019 you must respond with a written demand for a copy of the complaint. The demand must be sent or delivered to the court, whose address is 2841 6th St, Monroe, WI 53566-1902 and to Gray & Associates, L.L.P., plaintiff's attorney, whose address is 16345 West Glendale Drive, New Berlin, WI 53151-2841. You may have an attorney help or represent you. If you do not demand a copy of the complaint within 40 days, the court may grant judgment against you for the award of money or other legal action requested in the complaint, and you may lose your right to object to anything that is or may be incorrect in the complaint. A judgment may be enforced as provided by law. A judgment awarding money may become a lien against any real estate you own now or in the future, and may also be enforced by garnishment or seizure of property. Dated this 5th day of June, 2019.

Gray & Associates, L.L.P. Attorneys for Plaintiff 16345 West Glendale Drive New Berlin, WI 53151-2841 (414) 224-1987

Ian J. Thomson State Bar No. 1076280 Case No. 19-CV-000047

Gray & Associates, L.L.P. is attempting to collect a debt and any information obtained will be used for that purpose. If you have previously received a discharge in a chapter 7 bankruptcy case, this communication should not be construed as an attempt to hold you personally liable for the debt.

(June 19, 26, July 3, 2019) WNAXLP

Public Hearings

PUBLIC HEARING NOTICE

There will be a public hearing before the Green County Zoning and Land Use Committee relative to the following proposed Ordinance amendments to the Green County Zoning Code: Title 9, Chapter 2, Sanitary Code regulations (POWTS Maintenance assessments pursuant to Section 66.0703) The public hearing will be held in the Second Floor Conference Room, of the Green County Courthouse, 1016 16th Avenue, Monroe, Wisconsin, on Monday, July 8, 2019 at 4:00 p.m. All those who are concerned or affected by such action are urged to attend. A copy of the proposed ordinance is on file for inspection at the Zoning Office at 1016 16th Avenue, Monroe, during normal business hours. GREEN COUNTY ZONING ADMINISTRATION Adam M. Wiegel Zoning Administrator (June 12, 19, 2019) WNAXLP

Sheriff Marshall Sale

NOTICE OF SHERIFF’S SALE CASE NO. 17 CV 92 CASE CODE NO. 30404- FORECLOSURE

STATE OF WISCONSIN, CIRCUIT COURT GREEN COUNTY UNION BANK & TRUST COMPANY, Plaintiff vs. SWISS AIRE MOTEL, LLC, GLARNER BIER HAUS, LLC, AND ERIC L. GOBELI Defendants PLEASE TAKE NOTICE that by virtue of a judgment of foreclosure entered in the above entitled action on March 26, 2019, in the amount of $1,131,404.53, the undersigned Sheriff, of Green County, Wisconsin, will sell the described premises at public auction as follows: DATE/TIME: July 18, 2019 at 9:00 A.M. PLACE: Ground Floor Conference Room Green County Justice Center, 2841 6th St., Monroe, WI 53566 DESCRIPTION: Lots One (1) and Two (2) of Certified Survey Map No. 4925 recorded in Volume 22 of Certified Survey Maps of Green County on page 127, recorded in the office of the Register of Deeds for Green County, Wisconsin. Address: 1200-1201 State Hwy 69, New Glarus, Wisconsin53574 Parcel Nos. 23161 0610.0100 and 23161 0610.0200 TERMS: Pursuant to said judgment, 10% of the successful bid must be paid to the Sheriff at the sale in cash, cashier's check or certified funds, payable to the Clerk of Courts (personal checks cannot and will not be accepted). The balance of the successfull bid must be paid to the Clerk of COurts in cash, cashier's check or certified funds no later than ten (10) days after the court's confirmation of the sale,or the 10% down payment is forfeited to the plaintiff. The property is sold "AS IS" and is subject to all liens and encumbrances. Dated this 5th day of April, 2019

Jeffrey S. Skatrud Sheriff of Green County

Shannon Law Office, LLC Walter E. Shannon State Bar No. 1055751 Attorney for Plaintiff 104 W. Main St. Evansville, WI 53536 608-882-5944

Shannon Law Office, LLC is the creditor's attorney and is attempting to collect a debt on it's behalf. Any information obtained will be used for that purpose. If you have preciously received a Chapter 7 Discharge in Bankruptcy, this correspondence should not be construed as an attempt to collect a debt. (September 13, 20, 27, 2017) WNAXLP