Public Notices

Advertisement to Bid

Advertisement for Bids Pleasant View Nursing Home Facility Renovation Monroe, Green County, Wisconsin

Bid Opening: Thursday, May 27, 2021 at 1:00 p.m., C.S.T. The Pleasant View Nursing Home will receive sealed bids via the online electronic bid service through QuestCDN VBid online bidding or by sealed paper copy. Sealed paper bids shall be delivered to the Pleasant View Nursing Home located at N3150 State Hwy 81, Monroe, WI 53566 for the Pleasant View Nursing Home Facility Renovation. Both electronic and paper bids will be publicly opened and read aloud on Thursday, May 27, 2021 at 1:00 p.m., C.S.T. Description of Work: This Project consists of full window replacements and exterior metal panel installation, as well as existing restroom renovations and the construction of accessible restrooms. Work includes, but is not limited to, all demolition, framing, finishes, electrical, HVAC and plumbing. Bids shall be on a lump sum price basis with Alternates. Bidding Documents: The Issuing Office for the Bidding Documents is: Delta 3 Engineering, 875 S. Chestnut Street, Platteville, WI 53818, (608) 348-5355, mail@delta3eng.biz. Bidding Documents will be made available to Prospective Bidders by Monday, May 3, 2021. Prospective Bidders may examine the Bidding Documents at the Issuing Office on Mondays through Fridays between the hours of 8:00 a.m. and 4:30 p.m. CST. Printed Bidding Documents may be obtained from the Issuing Office during the hours indicated above for a non-refundable deposit of $145.00, including shipping, upon Issuing Office’s receipt of payment for the Bidding Documents. Digital version of the Bidding Documents also may be obtained online at QuestCDN.com using ebid doc #7786175 upon receipt of a non-refundable deposit of $40.00. Partial sets of Bidding Documents will not be available from the Issuing Office. Neither Owner nor Engineer will be responsible for full or partial sets of Bidding Documents, including Addenda if any, obtained from sources other than the Issuing Office. Consideration of Bids: No proposal will be accepted unless accompanied by a certified check or bid bond equal to at least five percent (5%) of the amount bid, payable to the OWNER as a guarantee that, if the bid is accepted, the Bidder will execute and file the proper contract and bond within 15 days after the award of the contract. The certified check or bid bond will be returned to the Bidder as soon as the contract is signed. If after 15 days the Bidder shall fail to do so, the certified check or bid bond shall be forfeited to the OWNER as liquidated damages. BIDDER is required to deliver the original certified check or bid bond within 72 hours of bid opening to Delta 3 Engineering, Inc., Attn: Ann Cooley, 875 S. Chestnut Street, Platteville, Wisconsin 53818. Bids may not be withdrawn within 90 days after the date of the bid opening. The OWNER reserves the right to increase or decrease the quantity of any item or portion of the work, or to omit portions of the work, as may be deemed necessary by the OWNER, and the same shall in no way affect or make void the contract, except that additions to, or deductions from, the contract price will be appropriately made. The OWNER reserves the right to waive any informalities, or to reject any or all bids, or any part of a bid, and to award the Contract to the Bidder, who in the judgment of the OWNER, will best serve the interest of the OWNER. A pre-bid conference will be conducted on site on Thursday, May 13, 2021 at 1:00 p.m., C.S.T. Bidders will not be prequalified. Additional Conditions: The letting of the work described herein is subject to the provisions of Sections 62.15, 66.0901, and 66.0903(1m) of the Wisconsin Statutes. This project is funded in part by a Community Development Block Grant CLOSE for Public Facilities (CDBG CL-PF) from the Wisconsin Department of Administration using federal CDBG funds. Wage Rates: The Contract shall be subject to Section 66.093 of the Wisconsin Statutes pertaining to municipal wage scales and Federal Davis-Bacon wage rates. Attention of bidders is particularly called to the requirements as to conditions of employment to be observed and minimum wage rates to be paid under contract, Section 3, Segregated Facility, Section 109 and E.O. 11246. Any contract or contracts awarded under this Advertisement for Bids may be funded in part by a grant from Community Development Block Grant Program. Minimum salaries and fringes to be paid on the Project shall be in accordance with the prevailing wage rate determination established by the Federal Department of Labor (DOL). Attention is also called to the fact that not less than the minimum salaries and fringes set forth in the Contract Documents must be paid on this Project, and that the Contractor must ensure that employees and applications for employment are not discriminated against because of their race, color, religion, sex, national origin, or other protected class. Federal Labor Standards program laws, including, but not limited to, the Davis-Bacon Act, the Copeland Anti-Kickback Act, and the Contract Work Hours and Safety Standards Act will apply to this Project. The Pleasant View Nursing Home encourages Minority-owned Business Enterprises (MBE’s), Women’s Business Enterprises (WBE’s), Disadvantaged Business Enterprises (DBE’s), and Small Businesses in Rural Areas (SBRA’s) to submit bids. A municipality, in awarding prime contracts, and primary contractor, in awarding subcontractors, are required to make a good faith effort to achieve a combined minimum goal of participation for MBE/WBE utilization in accordance with s.NR 162.09(3), Wis. Admin. Code. If a subcontractor awards subcontracts, these requirements shall apply to the subcontractor. Published by the authority of Pleasant View Nursing Home. By: Ms. Terry Snow Administrator N3150 State Hwy 81 Monroe, WI 53566 Date: Wednesday, April 28, 2021 (May 1, 5, 8, 12, 2021) WNAXLP

Debtors Creditors

NOTICE TO CREDITORS (INFORMAL ADMINISTRATION) CASE NO. 21-PR-33

STATE OF WISCONSIN, CIRCUIT COURT, GREEN COUNTY

IN THE MATTER OF THE ESTATE OF GARY L. HAWKINS Deceased PLEASE TAKE NOTICE: 1. An application for informal administration was filed. 2. The decedent, with date of birth March 10, 1938 and date of death April 17, 2021, was domiciled in Green County, State of Wisconsin, with a mailing address of W529 Theresa Court, Brodhead, WI 53520. 3. All interested persons waived notice. 4. The deadline for filing a claim against the decedent’s estate is August 16, 2021. 5. A claim may be filed at the Green County Justice Center, 2841 6th Street, Monroe, Wisconsin.

Thomas J. Vale Circuit Court Judge April 26, 2021

Atty. Robb E. Leach 916 17th Ave. Box 710 Monroe, WI 53566 608-325-2191 Bar Number 1082487

(May 1, 8, 15, 2021) WNAXLP

Miscellaneous

Regular Meeting of the Board of Education of the School District of Monroe was held on April 12, 2021

1. Call to Order: Rich Deprez, Board of Education President called the meeting to order at 7:00 P.M. 2. Roll Call: Board Members Present: Dan Bartholf, Mary Berger, Rich Deprez, Teresa Keehn, Nikki Matley, Cheryl McGuire, Dylan McGuire, Jim Plourde, and Tim Wolff - Administration Present: Brian Boehm, Chris Medenwaldt, Joe Monroe, Terri Montgomery, Ron Olson, Todd Paradis, Amy Timmerman, Jenna Trame, and Rick Waski 3. Motion to Suspend the Application of Policy 0161 – Motion by Mary Berger and seconded by Nikki Matley - Approved 4. Approve Agenda – Motion by Teresa Keehn and seconded by Nikki Matley to amend agenda – Approved – Motion to approve the amended agenda by Jim Plourde and seconded by Mary Berger - Approved 5. Recognitions 6. Public Comment 7. Consent Items – A. Approve Minutes – B. Approval of Support Staff Resignation – C. Approval of Support Staff Retirement – D. Approval of Professional Staff Hiring – E. Approval/Acceptance of Community Donations – Motion by Dan Bartholf and seconded by Jim Plourde - Approved 8. Old Business – 9. New Business – A. Informational Item – Reduction of School Psychologist Position (.8 FTE) – B. Informational Item – Reduction to 7-sections for Kindergarten for 2021-2022 School Year – C. Approval of 2021-2022 Professional Staff Contracts – Motion by Teresa Keehn and seconded by Jim Plourde – Approved – D. Approval of 2021-2022 Base Wage Agreement with MEA – Motion by Dan Bartholf and seconded by Nikki Matley – Approved – E. Approval of 2021-2022 Base Wage Agreement with MASS – Motion by Jim Plourde and seconded by Teresa Keehn – F. Approval of Firewall Update – Motion by Tim Wolff and seconded by Teresa Keehn – Approved – G. Approval to Change the Name of the Monroe Alternative Charter School Building – Motion by Nikki Matley and seconded by Dan Bartholf – Approved – H. 2020-2021 COVID-019 Operations Planning Update – I. Northside Project Update – J. Approval of Resolution to Allow WTCS Schools to Grant Associate Degrees – Motion by Teresa Keehn and seconded by Nikki Matley - Approved 10. Informational Items – A. Boardsmanship/Administration – B. Board of Education Correspondence – C. Committee Reports – D. Agenda Items for Future Discussion – E. Liaison Reports 11. Five Minutes for the Press 12. Closed Session - At 9.26 P.M. motion by Mary Berger and seconded by Jim Plourde to convene into Closed Session according to Wisconsin Statutes 19.85(1)(c) for the purpose of discussing preliminary notice of non-renewal. – 9/Yes-0/No-0/Abstain-0/Absent 13. Motion to Return to Open Session – At 9:34 P.M. motion by Teresa Keehn and seconded by Jim Plourde – Approved 14. Approval of Notice of Non-Renewal – Motion by Dan Bartholf and seconded by Mary Berger - Approved 15. Adjournment – At 9:37 P.M. motion by Mary Berger and seconded by Jim Plourde - Adjourned (May 1, 2021) WNAXLP

Name Changes

NOTICE AND ORDER FOR NAME CHANGE HEARING Case No. 21-CV-68

STATE OF WISCONSIN, CIRCUIT COURT, GREEN COUNTY

IN THE MATTER OF THE NAME CHANGE OF: ISABELLA JADE HAYES NOTICE IS GIVEN: A petition was filed asking to change the name of the person listed above: From: ISABELLA JADE HAYES To: ISABELLA JADE CARNES-ANDREWS Birth Certificate: ISABELLA JADE HAYES IT IS ORDERED: This petition will be heard in the Circuit Court of Green County, State of Wisconsin:

BY: Honorable James R. Beer PLACE: Via Zoom Instructions to Appear by Zoom DATE:

June 3, 2021 TIME: 9:45 am If you require reasonable accommodations due to a disability to participate in the court process, please call 608-328-9433 at least ten (10) working days prior to the scheduled court date. Please note that the court does not provide transportation.

BY THE COURT: James R. Beer Circuit Court Judge April 15, 2021

(April 24, May 1, 8, 2021)

WNAXLP

Public Hearings

LEGAL NOTICE:

There will be a public hearing before the Green County Board of Adjustment to consider an application for a conditional use permit from Lenzlinger Rentals LLC, landowner: for the operation of a boarding house (vacation rental). The land is zoned agricultural, and is located at N8984 Old Madison Road, Section 11, T4N-R7E, Town of New Glarus. The public hearing will be held in the County Board Room at the Green County Courthouse, 1016 16th Avenue, Monroe, Wisconsin on Wednesday, May 19, 2021 at 7:30 p.m. All those who are concerned or affected by such action are urged to attend. GREEN COUNTY ZONING ADMINISTRATION Adam M. Wiegel Zoning Administrator (May 1, 5, 2021) WNAXLP

Sheriff Marshall Sale

NOTICE OF SHERIFF’S SALE CASE NUMBER 17-CV-448 CASE CODE: 30404

STATE OF WISCONSIN, CIRCUIT COURT, GRANT COUNTY WISCONSIN BANK & TRUST Plaintiff, vs. ZACHARY R. LEAVER Defendant. By virtue of and pursuant to a Judgment entered in the above-entitled action on the 23rd day of April, 2018, in the Circuit Court of Grant County, Wisconsin, I will sell at public auction at the Green County Justice Center - Ground Floor Conference Room, 2841 6th Street, Monroe, Green County, Wisconsin, on the 6th day of May, 2021 at 9:00 a.m. all of the following mortgaged premises: W3057 Greenbush Road Town of Sylvester Juda, Green County, Wisconsin 53550 Parcel #s 23-028-0280.0100; 23-028-0280.0200; and 23-028-0410.0000 The Northwest Quarter of the Southeast Quarter and the East One-Half of the Southwest Quarter of Section 26, Town 2 North, Range 8 East, Town of Sylvester, Green County, Wisconsin. ALSO: The North One-Half of the Northeast Quarter of the Northwest Quarter of Section 35, Town 2 North, Range 8 East, Town of Sylvester, Green County, Wisconsin. The above described property includes: Lot One (1) of Certified Survey Map No. 4870 as recorded in Volume 21 of Certified Survey Maps of Green County on Page 296-299 as Document No. 564707. TERMS OF SALE: Cash Down payment of 10% of amount bid by certified check Balance due upon confirmation of sale. Dated at Monroe, Wisconsin this 9th day of April, 2021. Jeff Skatrud, Green County Sheriff KOPP MCKICHAN, LLP Attorneys for Plaintiff 44 East Main Street P.O. Box 253 Platteville, WI 53818 Telephone: 608-348-2615 (April 17, 24, May 1, 2021) WNAXLP