Public Notices

Advertisement to Bid

SECTION 00 11 13 ADVERTISEMENT FOR BIDS

Sealed bids for the construction of: BLACK HAWK SCHOOL DISTRICT ADDITION AND REMODEL REBID DOCUMENTS 202 EAST CENTER STREET SOUTH WAYNE, WISCONSIN 53587 will be received by: BLACK HAWK SCHOOL DISTRICT 202 EAST CENTER STREET SOUTH WAYNE, WISCONSIN 53587 WILLY CHAMBERS, ED. D. - DISTRICT ADMINISTRATOR until 2:00pm February 28, 2023, after which they will be opened publicly and read aloud. Bids received after the time set for receipt of bids will not be accepted. In general, the Project is an addition to and remodel of an existing school building. Work includes concrete foundations and slabs; masonry; structural steel, steel joists and decking; spray foam insulation; metal siding; EPDM roofing; tie-ins to existing steel roofing; hollow metal frames, flush wood doors, aluminum storefront coiling doors, and fire-rated aluminum entrances; gypsum assemblies; acoustical ceiling, painting, information specialties, plastic toilet compartments and accessories; and metal lockers. Plumbing work includes: water, sanitary, storm and gas. Mechanical work includes roof top unit, unit ventilators, and air distribution devices. Electrical work includes: lighting, power, and low voltage systems. Site work for the project includes: demolition of site components, modifications to gas, water, sanitary, storm drain, electric utilities; paving, grading landscaping, chain-link and decorative fencing. There are seven bid alternates. One of them includes demolition of an existing 3 story attached structure. Lump-sum Bids will be received on a SINGLE PRIME CONSTRUCTION CONTRACT FOR THE work described in the bidding documents. The owner will obtain separate contracts for Abatement/Demolition of an existing portion of the existing building and construction of an accessory building. The Project Drawings, Project Manual and other Bidding Documents may be examined at the following locations: AE'S OFFICE: HSR ASSOCIATES, INC. 100 MILWAUKEE STREET LA CROSSE, WI 54603 608-784-1830 BUILDER'S EXCHANGES: LA CROSSE, WI NORTHWEST REGIONAL (EAU CLAIRE/CHIPPEWA FALLS) WAUSAU, WI BUILDERS EXCHANGE OF WISCONSIN (APPLETON) MINNEAPOLIS, MN ROCHESTER, MN NORTHERN IA (MASON CITY, IA) MASTER BUILDERS IA (DES MOINES, IA) BUILDERS EXCHANGE OF MICHIGAN CONSTRUCTCONNECT DODGE DATA & ANALYTICS (WEST ALLIS, WI) Electronic Bidding Documents (.pdf) will be available from HSR Associates, Inc. via Sharefile electronic distribution. Contact Toni Furlano at tfurlano@hsrassociates.com. Bidding Documents will also be distributed to the Builders Exchanges listed above. Electronic versions of addenda will be distributed via the same systems. Hardcopy Bidding Documents may be picked up at HSR Associates' office. Bidders may request shipment of hardcopies by sending a check made out to HSR Associates in the amount of $25.00. The shipping fee will not be refunded and must be received prior to shipment. HSR Associates is responsible for distribution of addenda only to those who have requested project documents from HSR in formats described above. HSR Associates will make AutoCAD files available to the Contractor following award of contract. HSR Associates maintains a plan holder list at www.hsrassociates.com. This list includes only those who have requested plans from HSR and those who have requested to be added our list. Bid Security in the amount of Five Percent (5%) of the maximum amount of the Bid must accompany each Bid as described in the Project Manual, Instructions to Bidders. The Owner reserves the right to waive irregularities and to reject any or all Bids. Bids may only be withdrawn in accordance with the Project Manual, Instructions to Bidders. A non-mandatory pre-bid meeting will be conducted by the Owner and Architect/Engineer to answer questions and to enable bidders to examine conditions at the Project Site. Pre-Bid meeting will occur at 11:00am February 14, 2023 at the Main Office. By: Willy Chambers, Ed. D. Title: District Administrator (February 15, 22, 2023) WNAXLP

Debtors Creditors

NOTICE TO CREDITORS (INFORMAL ADMINISTRATION) CASE NO. 23-PR-04

STATE OF WISCONSIN, CIRCUIT COURT, GREEN COUNTY

IN THE MATTER OF THE ESTATE OF HANS A. SULZER Deceased. PLEASE TAKE NOTICE: 1. An application for informal administration was filed. 2. The decedent, with date of birth November 8, 1931 and date of death November 21, 2022 was domiciled in Green County, State of Wisconsin, with a mailing address of W4661 Sulzer Road, Monroe, WI 53566. 3. All interested persons waived notice. 4. The deadline for filing a claim against the decedent’s estate is May 19, 2023 5. A claim may be filed at the Green County Justice Center, 2841 6th Street, Monroe, Wisconsin.

Faun Marie Phillipson Circuit Court Judge February 15, 2023

Attorney Todd W. Schluesche 250 N. 18th Avenue, Suite 106 Monroe, WI 53566 608-325-2500 Bar Number 01024392

(February 22, March 1, 8, 2023) WNAXLP

NOTICE TO CREDITORS (INFORMAL ADMINISTRATION) CASE NO. 23-PR-13

STATE OF WISCONSIN, CIRCUIT COURT, GREEN COUNTY

IN THE MATTER OF THE ESTATE OF SABRINA M. FOLEY Deceased PLEASE TAKE NOTICE: 1. An application for informal administration was filed. 2. The decedent, with date of birth May 14, 1980, and date of death December 9, 2022, was domiciled in Green County, State of Wisconsin, with a mailing address of 2109 16th St., Monroe, WI 53566. 3. All interested persons waived notice. 4. The deadline for filing a claim against the decedent’s estate is May 25, 2023. 5. A claim may be filed at the Green County Justice Center, 2841 6th Street, Monroe, Wisconsin.

Faun Marie Phillipson Circuit Court Judge February 17, 2023

Attorney John C. Sauer Kittelsen, Barry, Wellington & Thompson S.C. 916 17th Ave. Box 710 Monroe, WI 53566 608-325-2191 Bar Number 1122523

(February 22, March 1, 8, 2023) WNAXLP

Foreclosures

NOTICE OF FORECLOSURE SALE CASE NO. 22-CV-000155

STATE OF WISCONSIN CIRCUIT COURT GREEN COUNTY

CAG NATIONAL FUND I LLC Plaintiff, vs. THE ESTATE OF CATHERINE TREUTHARDT, DECEASED Defendants. PLEASE TAKE NOTICE that by virtue of a judgment of foreclosure entered on December 13, 2022 in the amount of $179,519.03 the Sheriff will sell the described premises at public auction as follows: TIME: March 30, 2023 at 9:00 a.m. TERMS: Pursuant to said judgment, 10% of the successful bid must be paid to the sheriff at the sale in cash, cashier’s check or certified funds, payable to the clerk of courts (personal checks cannot and will not be accepted). The balance of the successful bid must be paid to the clerk of courts in cash, cashier’s check or certified funds no later than ten days after the court's confirmation of the sale or else the 10% down payment is forfeited to the plaintiff. The property is sold ‘as is’ and subject to all liens and encumbrances. PLACE: Green County Justice Center, 2841 6th Street, Ground Floor Conference Room, Monroe, WI DESCRIPTION: LOT THREE (3) OF BLOCK THREE (3) OF FIRST ADDITION TO MANSION ESTATES, CITY OF MONROE, GREEN COUNTY, WISCONSIN. PROPERTY ADDRESS: 1412 Parkview Dr. Monroe, WI 53566-1129 DATED: January 19, 2023

Gray & Associates, L.L.P. Attorneys for Plaintiff 16345 West Glendale Drive New Berlin, WI 53151-2841 (414) 224-8404

Please go to www.gray-law.com to obtain the bid for this sale. Gray & Associates, L.L.P. is attempting to collect a debt and any information obtained will be used for that purpose. If you have previously received a discharge in a chapter 7 bankruptcy case, this communication should not be construed as an attempt to hold you personally liable for the debt.

(February 22, March 1, 8, 2023) WNAXLP

Miscellaneous

PUBLICATION SUMMONS AND NOTICE Case no.: 2023CV000207 Classification Code: 30301 The amount claimed is over $10,000.

STATE OF WISCONSIN, CIRCUIT COURT, DANE COUNTY ONEMAIN FINANCIAL GROUP, LLC AS SERVICER FOR ("ASF") WILMINGTON TRUST, N.A., AS ISSUER LOAN TRUSTEE FOR ONEMAIN FINANCIAL ISSUANCE TRUST 2019-A 601 NW Second Street Evansville IN 47708 Plaintiff, vs. HUNTER R. JENSEN 107 4TH ST BRODHEAD, WI 53520-1127 Defendant.

PUBLICATION SUMMONS THE STATE OF WISCONSIN, To the person named above as a defendant: You are hereby notified that the plaintiff named above has filed a lawsuit or other legal action against you. The complaint, which is attached, states the nature and basis of the legal action. Within 40 (forty) days after February 16, 2023, you must respond with a written answer, as that term is used in Chapter 802 of the Wisconsin Statutes, to the complaint. The court may reject or disregard an answer that does not follow the requirements of the statutes. The answer must be sent or delivered to the court, whose address is 215 South Hamilton Street Madison, WI 53703-3285 and to Dobberstein Law Firm, LLC, the plaintiff's attorneys, whose address is 225 S. Executive Drive, Brookfield, Wisconsin 53005. You may have an attorney help or represent you. If you do not provide a proper answer within 40 (forty) days, the court may grant judgment against you for the award of money or other legal action requested in the complaint, and you may lose your right to object to anything that is or may be incorrect in the complaint. A judgment may be enforced as provided by law. A judgment awarding money may become a lien against any real estate you own now or in the future, and may also be enforced by garnishment or seizure of property. Dated this 10th day of February, 2023. DOBBERSTEIN LAW FIRM, LLC Attorneys for the plaintiff Electronically signed by Ashley M Nelson Ashley M Nelson State Bar No. 1086258 MAILING ADDRESS: 225 S. Executive Dr. Brookfield, WI 53005 (262) 641-3715 (February 15, 22, March 1, 2023) WNAXLP

PROCEEDINGS OF THE GREEN COUNTY BOARD OF SUPERVISORS February 14, 2023

County Boardroom, Green County Courthouse, 1016 16th Ave, Monroe, WI Jerry Guth, Chair, called the meeting to order at 7:00 p.m. The Clerk read the roll call with 28 present, 2 excused absences being Nelson and Schwartz and 1 tardy being Hartwig. The Board recited the Pledge of Allegiance. Sheriff Jeff Skatrud presented awards to various Green County deputies, jailers, dispatchers and detectives. Motion by Roemer, seconded by Carlson to approve the minutes of the January 10, 2023, meeting. Motion carried by a unanimous voice vote. RESOLUTION 2-1-23 Resolution Eliminating and Creating PVNH Positions WHEREAS, County Code 1-7-4 directs and charges the Personnel and Labor Relations Committee with the responsibility for considering and recommending requests for employee reclassification, creation and description of new positions and associated grades. NOW, THEREFORE, BE IT RESOLVED, by the Green County Board of Supervisors, in legal session assembled, that the Board consider the recommendation of the Personnel and Labor Relations Committee for the following position modifications at Pleasant View Nursing Home: Eliminate: Unit: Pleasant View Nursing Home Title: RN-Registered Nurse Grade: M Status: Full-time 40 hrs per week, non-exempt Minimum/Maximum Hourly Rate: $27.69 to $34.64 Benefits: All county fringe benefits Effective Date: February 19, 2023 Tax Levy: 0 Proposed: Unit: Pleasant View Nursing Home Title: Dementia Nursing Coordinator Grade: P Status: Full-time 40 hrs per week, non-exempt Minimum/Maximum Hourly Rate: $30.28 to $39.12 Benefits: All county fringe benefits Effective date: February 19, 2023 Tax Levy: 0 SIGNED: PERSONNEL AND LABOR RELATIONS COMMITTEE Jerry Guth, Chair Harvey Mandel, Vice-Chair Kristi Leonard Richard Thoman Linda Boll Michael Furgal Motion by Furgal, seconded by Oemichen to approve Resolution 2-1-23. Motion carried by a unanimous voice vote. Clerk Arianna Voegeli updated the board on the incident that occurred in the historic courthouse regarding dust from the construction company grinding bricks on the outside of the building. Clerk Voegeli also reminded the board that Tuesday, February 21, 2023, are elections. Motion by Larson, seconded by Snow to appoint Harvey W. Kubly to the Rail Transit Commission for a 3-year term expiring on February 14, 2026, and to appoint Brian Bucholtz as Corporation Counsel for a 2-year term. Motion carried by a unanimous voice vote. The UW-Extension Annual Report and Ordinance 23-0301 (Modification to ATV/UTV Regulations) were distributed. Motion by Kubly, seconded by Mandel to adjourn at 7:31 p.m. Motion carried by a unanimous voice vote. STATE OF WISCONSIN ) )SS COUNTY OF GREEN ) I, Arianna L. Voegeli, County Clerk, in and for said County, do hereby certify that the above and foregoing is a true and correct copy of the proceedings of the County Board of Supervisors of Green County, Wisconsin, on their meeting of February 14, 2023, A.D. Arianna L. Voegeli Green County Clerk (February 22, 2023) WNAXLP